Terms of Service
By accessing or using this website (the “Site”) or engaging Alex Serratos, doing business as Digital AI Ads (“Digital AI Ads,” “we,” “us,” “our”) for any service, you (“Client,” “you”) agree to be bound by these Terms of Service (the “Terms”). If you do not agree, do not use the Site or our services.
1. Services Description
Digital AI Ads designs and builds custom landing pages for service-business owners (fence installation, landscaping, concrete and foundation, pool service, auto detailing, plumbing, and similar trades) primarily serving the San Antonio and Houston, Texas markets. Each engagement is delivered as a one-time, fixed-fee build; ongoing maintenance and marketing services are not included.
2. Fees and Payment
The flat fee for a custom landing-page build is one thousand two hundred U.S. dollars ($1,200.00), payable in full prior to project start unless otherwise agreed in writing. We accept payment by credit card, ACH, or another method we agree on with you. Domain registration, hosting fees, and any third-party tooling required by Client (typically less than $30/month) are not included and are paid by Client directly to the relevant providers.
3. Scope of Work
Each $1,200 build includes:
- One discovery call (approximately 15 minutes)
- Custom design and code
- Copywriting based on Client-provided business information
- Mobile-responsive optimization
- One contact form wired to Client's email inbox
- One round of revisions before launch
- Launch and basic post-launch monitoring during the first week
Anything not listed above — including but not limited to additional revision rounds, additional pages or sections, custom integrations, ongoing maintenance, content updates, advertising campaigns, search-engine optimization, or copywriting beyond the agreed scope — is not included and is available at our then-current rates as a separate engagement.
4. Delivery Timeline
Subject to Section 5, we will design, build, and launch a Client's site within forty-eight (48) business hours after both (a) receipt of full payment and (b) approval of the project brief by Client. Business hours exclude weekends, U.S. federal holidays, and any period during which we are awaiting required information, assets, or approvals from Client.
5. Client Responsibilities
Client agrees to:
- Provide accurate, complete information about the business, services offered, service area, and any preferences during discovery
- Provide brand assets (logo, photos, etc.) or authorize us in writing to source comparable stock assets on Client's behalf
- Approve the project brief in a timely manner
- Provide feedback on the build within forty-eight (48) hours of the review-link delivery
- Pay any third-party costs (domain, hosting, ad spend) directly to the relevant providers
Delays caused by Client (delayed assets, delayed approvals, delayed feedback) do not count against the 48-hour delivery commitment in Section 4 and may extend the delivery date on an hour-for-hour basis.
6. Intellectual Property
Upon receipt of full payment, Client owns the final delivered landing page, including the custom code, copy, and design files prepared specifically for Client. Client receives the right to host the site on any hosting provider of Client's choice.
We retain:
- The right to display the finished site in our portfolio, case studies, social media, and marketing materials, including identifying Client by business name and city, unless Client opts out in writing before launch
- All ownership of pre-existing tools, frameworks, libraries, fonts, and stock assets used to produce the site (these are licensed to Client as part of the deliverable, not transferred)
- Ownership of generic patterns, methods, and know-how used in producing the site
7. Refunds and Cancellations
If Client cancels in writing before the discovery call has taken place, Client is entitled to a full refund.
Once the discovery call has occurred and the project brief has been approved, the project is considered started and all sales are final. We do not offer partial refunds for cancellations during the build process. This reflects the up-front design and copywriting work that begins immediately after brief approval.
8. Warranties and Disclaimers
We warrant that the delivered site will materially conform to the agreed brief at the time of launch. We make no guarantees about specific business outcomes — including but not limited to the number of leads, calls, customers, jobs booked, revenue, or search rankings the Client's business may receive after launch. Marketing results depend on factors outside our control: Client's offer, pricing, response time, geography, competition, ad spend, seasonality, and Client's own follow-up practices.
Except for the express warranty in this Section, the Site and our services are provided “as is” and “as available” without any other warranty, express or implied, including warranties of merchantability, fitness for a particular purpose, or non-infringement, except as required by applicable law.
9. Limitation of Liability
To the maximum extent permitted by law, our total aggregate liability to Client for any claim arising out of or relating to these Terms or the services we provide will not exceed the total fees paid by Client to Digital AI Ads in the twelve (12) months preceding the claim. We are not liable for indirect, consequential, incidental, special, exemplary, or punitive damages, including lost profits or lost business opportunities, even if advised of the possibility of such damages.
10. Indemnification
Client agrees to indemnify, defend, and hold harmless Digital AI Ads, its owners, and its representatives from any third-party claim, demand, loss, or expense (including reasonable attorneys' fees) arising out of (a) Client's content, claims, photographs, or representations on the delivered site, (b) Client's use of the site after launch, (c) Client's breach of these Terms, or (d) Client's violation of any applicable law or third-party right.
11. Texas DTPA Acknowledgment
Client acknowledges that the services we provide are commercial and not consumer goods or services as that term is used in the Texas Deceptive Trade Practices Act (DTPA), Texas Business and Commerce Code §17.41 et seq. To the extent permitted by law, Client waives all rights and remedies under the DTPA. This waiver is binding on Clients with assets or annual receipts of $5 million or more under DTPA §17.42(a); for Clients below that threshold, this waiver is included as evidence of the parties' intent.
12. Governing Law
These Terms are governed by the laws of the State of Texas, without regard to its conflict-of-laws principles.
13. Dispute Resolution
Binding arbitration. Any dispute, claim, or controversy arising out of or relating to these Terms or our services will be resolved by binding arbitration administered by the American Arbitration Association (AAA) under its Commercial Arbitration Rules then in effect. The arbitration will be conducted in Bexar County, Texas, by a single arbitrator. The arbitrator's decision is final and binding, and a judgment on the award may be entered in any court of competent jurisdiction.
Small-claims carve-out. Either party may bring an individual claim that qualifies for resolution in the small-claims court of Bexar County, Texas, in lieu of arbitration.
No class actions. All claims must be brought in the parties' individual capacity, not as a plaintiff or class member in any purported class, consolidated, or representative proceeding. The arbitrator may not consolidate claims or preside over any form of representative or class proceeding.
14. Modifications
We may update these Terms from time to time. Updates will be posted at this URL with a new “Last updated” date. Continued use of the Site or our services after the updated Terms are posted constitutes acceptance of the revised Terms.
15. Severability
If any provision of these Terms is held by an arbitrator or court of competent jurisdiction to be unenforceable, the remaining provisions remain in full force and effect, and the unenforceable provision will be modified to the minimum extent necessary to make it enforceable.
16. Messaging Terms (SMS)
Digital AI Ads sends transactional and promotional SMS (text) messages to phone numbers you provide through our forms or in direct communication with us. Your use of SMS communications from us is governed by these messaging terms in addition to our Privacy Policy.
Use cases. Transactional messages include discovery-call confirmations, project updates, support responses, and inquiry follow-ups. Promotional messages include service availability, capacity announcements, and offers.
Message frequency. Message frequency varies, typically 1–4 messages per month for opted-in subscribers.
Message and data rates. Standard message and data rates from your mobile carrier may apply.
Opt-out and help. Reply STOP to any message to unsubscribe at any time. Reply HELP for assistance, or contact us at legal@digitalaiads.com.
Carrier liability. Mobile carriers (Verizon, AT&T, T-Mobile, etc.) are not liable for delayed or undelivered messages. Message delivery is on a best-effort basis.
Age requirement. You must be at least 18 years old to provide a phone number for SMS communications. By submitting your phone number, you represent that you are 18 years of age or older.
Privacy. SMS-related data is handled per our Privacy Policy. Mobile information (phone numbers, SMS opt-in records) is not shared with third parties or affiliates for marketing purposes.
17. Contact
Alex Serratos d/b/a Digital AI Ads
10639 Fannin Way
San Antonio, TX 78214
(346) 399-5606
legal@digitalaiads.com